dear Sir
• We booked a flat in Eco village II and we were allotted unit E2- 703 in Eco Village on 1-9-2010. This flat was in construction Linked Plan and loan was sanctioned by IDBI.
• In July 2011 Hon’ble supreme court gave the judgement regarding Shahberi village. Our unit was affected. Bu this time i.e. July 2011 we had paid a sum of Rs. 6,37,462 to Supertech
• After the judgement we demanded we demanded our money from supertech with interest which they refused and offered us a unit D2- 1901in Livingston.
• For this they got an acceptance letter signed from us in which it was clearly written that the new unit will be on the same terms and conditions and supertech will inform the bank and we will sign all the necessary papers.
• We did not agree for unit 1901 as we wanted on a lower floor. Supertech people told us that for the time being you accept it and later on we will shift you to lower floor. Supertech allotted D2-1901 in Livingston on 17th September 2011
• The payment schedule for 1901 was
• Installments • Inst. date • % • Amount
• Booking amount • 1.8.2011 • 10 • 346,704.00
• Within 30 days of booking • 15.9.2011 • 85 • 2,94,6980.00
• At the time of possession • 31.10.2012 • 5 • 173,351.00
• • • Total • 3,467,035.00
• Here interesting point is we signed acceptance letter on 10th August 2011. But SuperTech people can see future so they made this payment schedule.
• We kept on contacting Supertech people to write to bank for swapping of loan. Finally on 29th Jan. 2012 (although the date in letter in 29th Jan. 2011) SuperTech wrote to IDBI Bank for swapping/ Transfer of property.
• On 6th March 2013 Supertech reoffered us unit D2-501. i. e. at a lower floor in the same tower. Now see th the payment schedule
• Installments • Inst. date • % • Amount
• Booking amount • 1.8.2011 • 10 • 346,704.00
• Within 30 days of booking • 15.9.2011 • 85 • 3,94,6980.00
• At the time of possession • 30.04.2013 • 5 • 180,074.00
• • • Total • 3,467,035.00
• Here interesting thing is in the same tower we could have possession on 19th floor in October 2012 and for the 5th floor in April 13.
• Can anybody who receives the letter in March 12 can go by this schedule. When I asked the dealing hand at Super Tech he said “ MamY ye to formality hai. Aap logon ka to case hi alag hai . Aap is par mat Jaaiye.” We believed supertech and this was the biggest mistake we made.
• They started demanding swapping charges from us. For which we had to waste many casual leaves, just to go to SuperTech office and argue. Finally the matter resolved. But we went through a lot of harassment.
• In March 2012 we were told that in IDBI there is no such provision of swapping of loan. So we will have to first foreclose our earlier loan and then apply afresh
• We applied again and paid the processing fee for the same which Supertech promised to adjust at the time of Possession. Later IDBI refused to sanction the loan because some technical paper was missing from Builder’s side.
• We were told to apply in India Bulls. We applied but again since the technical paper was missing. Loan was not disbursed.
• Finally loan amount was disbursed by Corporation bank in July 2012.
• There after for the last three years there was nothing.
• Now in May 2015, Supertech gave us offer of Possession. In this they charged Rs. 5,41,767 as interest on delayed payment. This delayed payment includes the time before the judgememnt of hon’ble supreme court. As if Supertech people knew the judgement in advance and they also knew that we will shift to Livingston. Really surprising.
• When we visited supertech office, they said we can’t do anythong with financial component , Only director can touch this component. Now for the last 3 months we are being harassed both physicall and mentally. At least five times they have given us appointment with the director. When we go there director is not there. Then they will say “ AAj to sir aaye nahin. Waise roz 3 baje aate hai” you come on That day.
• When we met the CRM person he said “ aapaka case theek se present nahin hua hai ye component to lagan hi nahin chahiye” I will talk to director and present your case.
• Now they have sent us a revised demand letter in which now the interest on delayed payment is Rs.3,06000.
• Moreover, in the offer letter we were given open car parking. Now they are asking additional Rs. 77000/- for car parking
We have been cheated by supertech builders. It was delay on their part that they did not give the bank technical paper. Moreover, builder is not paying any penalty for delay in possession and charging us unnecessary. We want that this interest on delayed payment and parking charges should be waived off and we should be appropriately compensated for our harassment.